Terms & Conditions

These Terms and Conditions ("Terms") govern your use of the website www.ux-9.com operated by UX9 Ventures Pvt. Ltd. ("UX9", "Company"). By accessing this website or engaging our services, you agree to these Terms.

1. Acceptance of Terms

By using our website or services, you confirm that you are at least 18 years of age, have the legal authority to enter into agreements, and agree to be bound by these Terms and our Privacy Policy.

2. Services

UX9 provides turnkey commercial interior design and build services, as well as residential contracting services across India. Our specific scope of work, deliverables, timelines, and commercial terms are defined in individual project agreements signed between UX9 and the client.

The information on this website is for general informational purposes only and does not constitute a contractual offer or guarantee of service delivery.

3. Intellectual Property

All content on this website — including but not limited to text, graphics, logos, images, design renderings, and project photography — is the intellectual property of UX9 Ventures Pvt. Ltd. or its licensors.

• You may not reproduce, distribute, modify, or use our content without prior written consent
• Project designs created by UX9 remain our intellectual property until full payment is received
• Client-shared designs, drawings, and specifications remain the property of the respective client

4. Project Inquiries & Quotations

Inquiries submitted through our website do not constitute a binding agreement. All project engagements are subject to a formal written agreement executed between both parties. Quotations provided are valid for 30 days from the date of issue unless otherwise specified.

5. Payment Terms

Payment terms are defined in individual project contracts and typically follow a milestone-based structure. Standard terms include:

• An advance payment before commencement of design or construction work
• Progress payments tied to defined project milestones
• Final payment upon project completion and handover

6. Project Execution

UX9 commits to executing projects to the standards defined in the project agreement. Any changes to scope, materials, or specifications post-agreement will be subject to a formal change order and may affect cost and timeline.

7. Client Responsibilities

Clients are responsible for:

• Providing timely approvals and decisions to avoid project delays
• Ensuring site access as required by the project schedule
• Providing all necessary permissions, NOCs, and approvals from relevant authorities
• Making payments on schedule as per the agreed contract

8. Limitation of Liability

UX9's liability for any claim arising from the use of this website or our services shall be limited to the fees paid by the client for the specific project in question. We are not liable for indirect, consequential, or incidental damages.

9. Confidentiality

Both parties agree to maintain confidentiality of sensitive project information, pricing details, and proprietary processes. UX9 may use project photography and general descriptions for marketing purposes unless explicitly prohibited in the project agreement.

10. Dispute Resolution

Any disputes arising from these Terms or project engagements shall be governed by the laws of India. Parties shall first attempt resolution through good-faith negotiation. Unresolved disputes shall be subject to arbitration under the Arbitration and Conciliation Act, 1996. Jurisdiction shall be Bengaluru, Karnataka.

11. Termination

Either party may terminate a project agreement as per the terms defined in the specific contract. This website may be modified or terminated at any time without prior notice.

12. Governing Law

These Terms are governed by the laws of the Republic of India. Any legal proceedings shall be subject to the exclusive jurisdiction of the courts in Bengaluru, Karnataka.

13. Contact

For questions regarding these Terms:

UX9 Ventures Pvt. Ltd.
Email: hello@ux-9.com
Phone: +91 96067 40777